Terms and Conditions

HomeTerms and Conditions

Terms and Conditions

Terms and Conditions

Last Updated: April 6, 2026

Welcome to Cura Roofing. These Terms and Conditions (“Terms”) govern your use of our website (https://curaroofing.com) and the roofing services provided by Cura Roofing (“Company,” “we,” “us,” or “our”). By accessing our website or engaging our services, you agree to be bound by these Terms.

1. Scope of Services

Cura Roofing provides residential and commercial roofing services, including but not limited to:

  • Roof inspections and leak detection.
  • Full roof replacements and installations.
  • Emergency repairs and maintenance.
  • Assistance with roofing-related insurance claims.

All services are subject to a written Service Agreement or Proposal which will detail the specific scope of work, materials, and project timeline.

2. Estimates and Proposals

  • Validity: Proposals are valid for 30 days from the date of issuance unless otherwise stated.
  • Hidden Conditions: Estimates are based on a visual inspection. If, upon removal of the existing roof, we discover hidden defects (e.g., rotted decking, structural issues, or improper ventilation), Cura Roofing will notify the Client immediately. Such repairs will incur additional costs and will be documented in a Change Order.
  • Price Fluctuations: Due to market volatility, we reserve the right to adjust pricing if material costs increase by more than 5% between the date of the proposal and the start of work.

3. Payment Terms

  • Deposit: A deposit of [Insert Percentage, e.g., 30%] is typically required before work commences or materials are ordered.
  • Progress Payments: For larger projects, progress payments may be required at specific milestones (e.g., material delivery, mid-project).
  • Final Payment: The balance is due immediately upon substantial completion of the project.
  • Late Fees: Unpaid balances will accrue interest at a rate of 1.5% per month (or the maximum allowed by law) starting 15 days after the invoice date.

4. Client Responsibilities

To ensure a successful project, the Client agrees to:

  • Access: Provide the Company and its crew access to the property, including driveways for equipment and electrical outlets for tools.
  • Safety: Keep children, pets, and unauthorized persons away from the work zone.
  • Permits: Unless otherwise agreed in writing, Cura Roofing will obtain standard building permits, but the Client is responsible for any HOA approvals or historical district clearances.
  • Interior Protection: Remove or secure fragile items, wall hangings, and electronics inside the home, as roofing work causes vibrations that may disrupt these items.

5. Scheduling and Delays

While we strive for timely completion, the Client acknowledges that roofing is weather-dependent. Cura Roofing is not liable for delays caused by:

  • Adverse weather conditions (rain, snow, extreme wind).
  • Supply chain disruptions or material shortages.
  • Acts of God (Force Majeure).

6. Warranties

  • Workmanship Warranty: Cura Roofing provides a [Insert Number, e.g., 5 or 10] year warranty on labor and installation. This covers defects resulting from the installation process only.
  • Manufacturer Warranty: Materials are covered by the manufacturer’s specific warranty. We will provide you with the necessary documentation to register these warranties.
  • Exclusions: Warranties are void if the roof is modified by a third party, damaged by “acts of God” (e.g., hail, fallen trees), or if the Client fails to make full payment.

7. Limitation of Liability

  • Pre-existing Conditions: Cura Roofing is not responsible for damage caused by pre-existing mold, structural rot, or improperly installed interior lines (gas, electric, water) located within 6 inches of the roof deck.
  • Incidental Damage: While we take precautions to protect landscaping and driveways, we are not liable for minor scuffs, cracks in aged asphalt/concrete, or minimal lawn disturbance standard for heavy construction.

8. Cancellation and Termination

  • Client Cancellation: In accordance with New York law, homeowners may have a “Cooling-Off Period” (typically 3 business days) to cancel a contract without penalty. Cancellations after this period may be subject to a restocking fee for materials and a 15% administrative fee.
  • Company Termination: We reserve the right to terminate the agreement if the site is found to be unsafe or if the Client breaches payment terms.

9. Governing Law

These Terms are governed by and construed in accordance with the laws of the State of New York. Any disputes arising from these Terms or our services shall be resolved in the courts of [Insert County, e.g., Albany County], NY.

10. Contact Information

For questions regarding these Terms, please contact us:

Address: 22 Laurel Ave, Schenectady, NY 12304

Email: info@curaroofing.com

Phone: 518-847-8354